In Triple Point Technology v PTT, the Supreme Court of the United Kingdom has restored the orthodox position on how termination prior to completion of work affects the operation of a liquidated damages...more
The Court of Appeal of England & Wales considered, in respect of a delayed software project, whether a liquidated damages provision survived termination of the contract....more
3/18/2019
/ Appeals ,
Breach of Contract ,
Calculation of Damages ,
Commodities Traders ,
Contract Termination ,
Contract Terms ,
Damages ,
Delay Claims ,
Delays ,
Liquidated Damages ,
Software Developers ,
UK
The High Court of England & Wales considered, in respect of the delayed completion of a solar project, the appropriate end date for liquidated damages under a terminated construction contract....more
2/5/2019
/ Calculation of Damages ,
Construction Contracts ,
Construction Disputes ,
Construction Industry ,
Contract Termination ,
Contract Terms ,
Delay Claims ,
Liquidated Damages ,
Power Plants ,
Solar Energy ,
Termination Clauses ,
UK